Terms & Conditions

These Terms & Conditions (“Agreement”) govern your relationship with Rainwolf Gutters (“we,” “us,” or “our”) and your use of our website and services. By accessing or using the Rainwolf Gutters website or engaging our services, you agree to be bound by this Agreement. If you do not agree with any part of these terms, you should not use our website or services.

1. Acceptance of Terms

By accessing the Rainwolf Gutters website or requesting services from Rainwolf Gutters, you agree to these Terms & Conditions and all applicable laws and regulations. This Agreement constitutes the entire understanding between Rainwolf Gutters and you regarding your use of our services and website.

2. Services and Estimates

Rainwolf Gutters provides gutter installation, gutter guard installation, repairs, and related services throughout South-Central Pennsylvania. Any estimate provided is not a guaranteed fixed price unless specified in writing. Estimates are based on current information and conditions; unforeseen issues may result in changes to scope and cost.

3. Free Estimates and Scheduling

Free estimates are provided at no obligation to the customer. Rainwolf Gutters will schedule on-site evaluations based on availability. Job start and completion dates are estimates and may change due to weather, material availability, or unforeseen conditions at the property.

4. Changes and Delays

Rainwolf Gutters is not liable for delays caused by events outside our control, including Acts of God, weather, supply shortages, labor issues, or permitting delays. In the event we cannot perform under the original scope due to unforeseen circumstances, we will notify you and propose appropriate adjustments.

5. Customer Responsibilities

Customers are responsible for ensuring access to the property and work areas at the agreed-upon time. Obstructions must be removed prior to arrival. Failure to provide access may result in rescheduling or additional charges.

6. Limitation of Liability

To the fullest extent permitted by law, Rainwolf Gutters and its representatives shall not be liable for any indirect, incidental, special, consequential, or punitive damages, including loss of profits, loss of property, or any damages arising from the services provided or inability to perform services.

Rainwolf Gutters’ total liability for any claim related to our services shall not exceed the amount paid by the customer for those services.

7. Payment Terms

Payment terms will be outlined in the estimate or contract provided at the time of agreement. A deposit may be required before work begins. Final payment is due upon completion unless otherwise specified in writing. Late payments may incur interest or collection costs as permitted by law.

8. Warranty and Workmanship

Rainwolf Gutters warrants workmanship for a specified period after completion (e.g., 12 months) as stated in your contract. Manufacturer warranties on materials supplied are separate and handled through the material provider. This warranty does not cover damage caused by:

Acts of God
Poor drainage unrelated to installation
Structural failure
Modifications by parties other than Rainwolf Gutters
Normal wear and tear

Please refer to the specific warranty document provided with your contract for complete terms.

9. Indemnification

You agree to indemnify and hold harmless Rainwolf Gutters and its employees, subcontractors, and agents from any claims, damages, liabilities, costs, or expenses arising out of:

Your misuse of services
Any breach of this Agreement
Any negligent or wrongful act by you or a third party

10. Arbitration and Dispute Resolution

Any dispute arising under this Agreement shall be resolved through binding arbitration in the county where Rainwolf Gutters operates, in accordance with the applicable rules of arbitration. Both parties waive the right to a jury trial. The arbitrator’s decision shall be final and binding.

11. Governing Law

This Agreement shall be governed by the laws of the Commonwealth of Pennsylvania, without regard to its conflict of law principles.

12. Changes to Terms

Rainwolf Gutters may modify these Terms & Conditions at any time. Revised terms will be posted on the website with an updated “Last Updated” date. Continued use of the website or services after changes constitutes acceptance of the new terms.

This Terms & Conditions document is adapted from a common contractor template and modified for Rainwolf Gutters’ business model.